Last Updated: 19 August 2026
Welcome to the website of Myland Global Marketing Sdn. Bhd. (“Myland Global Marketing”, “we”, “us”, or “our”).
By accessing this website or engaging our renovation and construction services, you agree to the following Terms & Conditions.
1. Our Services
Myland Global Marketing Sdn. Bhd. provides renovation and construction-related services, which may include:
- Residential Renovation
- Commercial Renovation
- Construction & Structural Work
- Interior Finishing
- Kitchen Renovation
- Bathroom Renovation
- Electrical Services
- Plumbing Services
- Exterior & Outdoor Works
- Design & Project Management
- Repair and maintenance services
The exact services provided will depend on the project quotation, scope of work, drawings, specifications, and written agreement between the client and the company.
2. Website Information
We make reasonable efforts to ensure that the information displayed on this website is accurate and up to date.
However:
- Images may be examples or representative project images.
- Colours, materials, finishes and products may vary from photographs.
- Project results may vary depending on the property and site conditions.
- Website information does not constitute a final quotation or construction contract.
The final scope, specifications, price and project schedule will be confirmed in the relevant quotation or contract.
3. Quotations
Any quotation provided by Myland Global Marketing is based on the information available at the time of preparation.
A quotation may include:
- Labour
- Materials
- Installation
- Transportation
- Site preparation
- Other agreed project costs
Unless specifically stated, a quotation does not automatically include additional work, government or authority fees, specialist professional fees, unforeseen structural problems, or changes requested by the client.
The quotation validity period will be stated in the quotation where applicable.
4. Scope of Work
The agreed scope of work should be clearly stated in the quotation, work order, drawings, specifications, or renovation contract.
Only work included in the agreed scope will be considered part of the original contract price.
For renovation projects, written documentation is important because it helps both the client and contractor understand their responsibilities and reduces uncertainty. CIDB provides standard contract terms specifically for renovation and small projects.
5. Payment Terms
Payment arrangements will be stated in the quotation or project agreement.
Depending on the project, payments may be scheduled according to:
- Deposit or initial payment
- Project milestones
- Materials or installation stages
- Progress claims
- Final payment
The client agrees to make payments according to the agreed payment schedule.
Late payments may affect the project schedule and may result in suspension of work until outstanding amounts are resolved.
6. Changes and Additional Work
Any change to the agreed scope of work may affect the project cost and completion date.
Additional or changed work should be approved in writing before the work is carried out.
This may include:
- Additional construction work
- Changes to materials
- Additional electrical points
- Additional plumbing work
- Changes to flooring or tiles
- Changes to kitchen or bathroom specifications
- Additional painting or finishing
- Client-requested design changes
A written Variation Order or other written approval may be used to record agreed changes.
CIDB guidance also recommends documenting variations in writing to reduce misunderstandings and disputes.
7. Project Schedule
We will make reasonable efforts to complete the project within the agreed timeframe.
However, the completion date may be affected by circumstances including:
- Client-requested changes
- Delayed approvals
- Material availability
- Site access problems
- Unforeseen site conditions
- Authority requirements
- Weather conditions
- Delays caused by third parties
- Events beyond our reasonable control
Where appropriate, the project schedule may be adjusted to reflect such circumstances.
8. Site Access
The client is responsible for providing reasonable access to the property during agreed working hours.
The client should ensure that:
- The work area is reasonably accessible.
- Personal valuables are removed or protected.
- Necessary information about the property is provided.
- Building management or relevant parties are informed where required.
Where access is unavailable or significantly restricted, project completion may be delayed.
9. Existing Property and Unforeseen Conditions
Renovation work may reveal conditions that could not reasonably be identified before work begins.
Examples may include:
- Hidden water leaks
- Concealed electrical wiring
- Damaged pipes
- Structural problems
- Termite damage
- Existing defects
- Uneven surfaces
- Hidden deterioration
If additional work is required, we will discuss the issue with the client and, where appropriate, provide a revised quotation or variation before proceeding.
10. Materials and Finishes
Materials will generally be supplied according to the agreed quotation or specifications.
Where a particular product, colour, model or material becomes unavailable, an alternative may be proposed for client approval.
Natural materials and manufactured products may have variations in colour, texture, pattern, size or appearance.
11. Workmanship and Defects
We aim to provide work that meets the agreed specifications and reasonable industry standards.
If the client identifies a workmanship issue covered by the agreed project terms, the client should notify us within the applicable defect or warranty period stated in the project agreement.
Defects caused by misuse, accidental damage, unauthorized modifications, normal wear and tear, or work performed by third parties may not be covered.
12. Electrical and Plumbing Work
Electrical and plumbing work will be carried out according to the agreed scope and applicable requirements.
Where specialist certification, inspection, approval, or licensed professional involvement is legally required, the applicable requirements will apply.
The client should not modify completed electrical, plumbing, structural, or other building works without appropriate professional advice.
13. Structural Work
Structural work may require appropriate drawings, professional assessment, approvals, permits, or qualified personnel depending on the project.
Structural works will be subject to the requirements applicable to the property and project.
The client is responsible for providing accurate information about existing plans and known structural conditions.
14. Permits and Approvals
Where permits, approvals, management permissions, or authority requirements are necessary, responsibility for obtaining them should be clearly stated in the quotation or project contract.
The project may be delayed if required approvals are not obtained on time.
15. Cancellation or Termination
Either party may have rights to terminate the project according to the terms stated in the signed quotation or renovation contract.
Termination may involve matters such as:
- Non-payment
- Material breach of contract
- Failure to provide site access
- Significant unauthorized changes
- Prolonged suspension of work
- Other circumstances specified in the contract
Any outstanding payment for completed work, approved materials, or other agreed costs may remain payable.
16. Project Images and Portfolio
With the client’s permission, we may use photographs of completed renovation work for our portfolio, website, social media, or marketing materials.
We will take reasonable steps to avoid publishing personal information or identifiable private details without appropriate permission.
Clients may contact us if they have concerns about the use of project images.
17. Website Intellectual Property
Unless otherwise stated, website content including:
- Company branding
- Logos
- Text
- Graphics
- Photographs
- Design elements
- Website layout
belongs to or is used by Myland Global Marketing Sdn. Bhd. with appropriate rights.
Website content may not be copied, reproduced, modified, or commercially used without permission.
18. Third-Party Links
Our website may contain links to third-party websites.
We are not responsible for the content, availability, security, or privacy practices of external websites.
Users should review the terms and privacy policies of third-party websites before using them.
19. Limitation of Liability
To the extent permitted by applicable law, Myland Global Marketing Sdn. Bhd. will not be responsible for losses arising from circumstances outside our reasonable control.
Nothing in these Terms & Conditions is intended to exclude or restrict any legal right or liability that cannot lawfully be excluded or restricted.
20. Complaints and Disputes
If you have a concern about our services, we encourage you to contact us first so that we can attempt to resolve the matter through discussion.
Where a formal dispute arises, the parties should follow the dispute-resolution procedure stated in the applicable project contract.
CIDB guidance identifies negotiation, mediation and arbitration as possible mechanisms for resolving construction disputes, depending on the contract.
21. Applicable Law
These Terms & Conditions shall be interpreted in accordance with the applicable laws of Malaysia.
Nothing in these Terms & Conditions prevents either party from exercising rights available under applicable Malaysian law.
22. Changes to These Terms
Myland Global Marketing Sdn. Bhd. may update these Terms & Conditions from time to time.
Updated terms will be published on this website with a revised “Last Updated” date.
23. Contact Us
For questions regarding these Terms & Conditions, quotations, renovation projects, or our services, please contact:
Myland Global Marketing Sdn. Bhd.
Business: Renovation & Construction Services
Email: mylandglobalmarketing@gmail.com
Phone: +60182551360
Address: A 1706 Level 17 Menara A, Persiaran MPAJ, Jalan Pandan Utama, Pandan Indah, 55100 Kuala Lumpur, Wilayah Persekutuan Kuala Lumpur Indah, Pandan Indah,
Myland Global Marketing Sdn. Bhd.
Residential Renovation • Commercial Renovation • Construction • Interior Finishi**ng • Kitchen • Bathroom • Electrical • Plumbing • Exterior Works • Project Management